TERMS & CONDITIONS – SOLARISE ENERGIES

Welcome to Solarise Energies Pvt. Ltd. By accessing or using our website
https://solariseenergies.com and/or engaging in our solar energy services, you agree to be bound by these Terms & Conditions.
Please read them carefully.

If you do not agree with any part of these Terms, please do not use the Site or our Services.
For questions, contact us at info@solariseenergies.com.

Introduction & Definitions

• “Services” refers to all solar energy solutions provided by us, including consultations, design, installation, maintenance, repairs, and monitoring.
• “User Content” refers to any information or material submitted to us through the website (e.g., inquiries, requests, feedback).

Use of the Site

• You agree to use the Site lawfully, responsibly, and in compliance with these Terms.
• You must be at least 18 years old to use the Site.
• You agree not to misuse or interfere with the Site, including transmitting harmful or illegal content.

Services

Scope

• We provide residential, commercial, and industrial solar energy services.
• Service timelines, components, and costs are defined in individual proposals or agreements.

Estimates & Quotes

• All estimates are non-binding until formally accepted by both parties.
• Quotes may be revised based on site survey results or regulatory changes.

Payment Terms

• Payment terms (deposit, milestones, final payment) are agreed per engagement.
• Interest may apply to late payments at the maximum rate permitted by law.

Scheduling & Site Access

• You grant us access to your premises for surveys, installation, maintenance, and inspections.
• Cancellations should be communicated at least 48 hours in advance.

Warranties & Disclaimers

• Workmanship and material warranties are as per your service agreement.
• Except as expressly stated, all implied warranties are disclaimed to the fullest extent permitted by law.

Limitation of Liability

• Our liability is limited to the total amount paid for the specific Service in dispute.
• We are not liable for indirect, consequential, or punitive damages (including loss of profits or data).

Intellectual Property

• All content on the Site (text, images, graphics, software, trademarks) is owned or licensed by Solarise Energies.
• You may use materials only for personal or internal business purposes — not for commercial resale or distribution.

Privacy & Data Protection

Your personal information is handled according to our Privacy Policy. By using the Site, you consent to its terms and agree to receive service-related communications and updates.

Force Majeure

We are not responsible for delays or failures caused by events beyond our reasonable control, including natural disasters, utility delays, supply shortages, or regulatory changes.

Termination

• These Terms remain in effect unless terminated.
• We may suspend or terminate Services or Site access if you breach these Terms, with or without notice.

Amendments

We may update these Terms at any time by modifying this page. Continued use of the Site or Services after updates signifies acceptance of the revised Terms.

Pricing

Our solar services range approximately from ₹50,000 – ₹50,00,000 (INR), depending on project scale and installation requirements.

Governing Law & Dispute Resolution

These Terms are governed by the laws of India. Any dispute will be resolved through arbitration or the courts of India, as stated in your service agreement.

Contact Us

For any questions or assistance, contact:

Solarise Energies
Email: info@solariseenergies.com